52 MONTEREY COUNTY WEEKLY NOVEMBER 30-DECEMBER 6, 2023 www.montereycountyweekly.com classifieds Legal Notices why the petition for change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two court days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing. Notice of hearing date Jan. 19, 2024 Time: 8:30 am Dept 13A. The address of the court is Superior Court of California, County of Monterey, 1200 Aguajito Rd, Monterey, CA 93940. A copy of this Order To Show Cause shall be published at least once each week for four successive weeks prior to the date set for hearing on the petition in the following newspaper of general circulation, printed in this county MONTEREY COUNTY WEEKLY. DATE Nov. 27, 2023. Judge of the superior court Carrie M. Panetta. Publication dates: Nov. 30, Dec. 7, 14, 21, 2023. ORDER TO SHOW CAUSE FOR CHANGE OF NAME: Petition of LAVONNA LEE GRIJALVA-ZIMMERMAN Case No. 23CV003823 Filed Nov. 27, 2023. To all interested persons Petitioner LAVONNA LEE GRIJALVA-ZIMMERMAN filed a petition with this court for a decree changing name as follows - present name LAVONNA LEE GRIJALVA-ZIMMERMAN to proposed name LA VONNA LEE ZIMMERMAN. THE COURT ORDERS that all persons interested in this matter appear before this court at the, hearing indicated below to show cause, if any, why the petition for change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two court days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing. Notice of hearing date Jan. 190 2024 Time: 8:30 am Dept 14. The address of the court is Superior Court of California, County of Monterey, 1200 Aguajito Rd, Monterey, CA 93940. A copy of this Order To Show Cause shall be published at least once each week for four successive weeks prior to the date set for hearing on the petition in the following newspaper of general circulation, printed in this county MONTEREY COUNTY WEEKLY. DATE Nov. 27, 2023. Judge of the superior court Carrie M. Panetta. Publication dates: Nov. 30, Dec. 7, 14, 21, 2023. Sale of Property NOTICE OF AUCTION SALE OF UNPAID MOVING AND STORAGE: In accordance with the provisions of the California Self Service Storage Facility Act Business and Professions Code, Sections 21700- 21716, there being due and unpaid rent, storage charges, fees and costs, notice is hereby given that the goods which are stored at Salinas Self Storage, 201 Harrison Road, Salinas, CA 93907 will be sold by unit at a PUBLIC AUCTION by A Ward Auction. This sale will take place on 12/12/23 at 10:15 a.m. and any following dates announced at the auction until all the goods are sold or ROB ROGERS NOTICE TO BIDDERS DOCUMENT 00 11 16 Notice is hereby given that the MONTEREY PENINSULA UNIFIED SCHOOL DISTRICT (hereinafter referred to as “Owner”) will receive sealed bids prior to the date and time stated for the Bid Opening for the award of a contract to construct the above-mentioned project. DISTRICT SERVICES CENTER EV BUS CHARGERS PROJECT #8262 WIRING PLAN for TEN (10) BUS CHARGERS District Services Center, 540 Canyon Del Rey Boulevard, Monterey, CA 93940 Engineer’s Estimate: $91,000.00 Brief Description: Wiring for ten (10) EV Bus Chargers Project Bidding Documents can be obtained from the District website at: www.mpusd.net/constructionbids The Owner reserves the right to add or deduct any of the additive or deductive items after the lowest responsible and responsive bidder is determined. The lowest bid shall be determined on the total amount of the base bid. The Owner may or may not decide to use the Alternative listed on the Bid Form. This Contract is subject to the California Public Contract Code 22032, any Public Works Project that is estimated to be below $200,000 is subject to the Informal Bidding Procedures set forth by the State of California Uniform Construction Cost Accounting Commission. Contractor must be on the MPUSD CUPCCA Vendor list at least five (5) days prior to bid. This is not subject to prequalification. Public works projects shall be subject to compliance monitoring and enforcement by the Department of Industrial Relations. A contractor or subcontractor shall not be qualified to submit a bid or to be listed in a bid proposal subject to the requirements of Public Contract Code section 4104 unless currently registered and qualified under Labor Code section 1725.5 to perform public work as defined by Division 2, Part 7, Chapter 1 (§§1720 et seq.) of the Labor Code. A contractor or subcontractor shall not be qualified to enter into, or engage in the performance of, any contract of public work (as defined by Division 2, Part 7, Chapter 1 (§§1720 et seq.) of the Labor Code) unless currently registered and qualified under Labor Code section 1725.5 to perform public work. The Contract Time shall be Thirty (30) calendar days, and liquidated damages for delay shall accrue. See Section 3 of the Agreement for details. Any questions on this project contact: Garrett Fonseca, garrett.fonseca@rgmkramer.com Cell 831.818.4584. Bids must be sealed and filed with the Owner’s Representative at the following location: Monterey Peninsula Unified School District BOND FACILITY OFFICE 540 Canyon Del Rey Boulevard, Suite 1 Monterey, CA 93940 on Tuesday, December 19, 2023, before 2:00:00 P.M. on the clock designated by the Owner or its representative as the bid clock (Atomic Clock located just inside Suite 1, MPUSD Bond Office), after which they shall be opened. No bid will be accepted by the Owner after this time. Facsimile (FAX) copies of the bid will not be accepted. There will be a Mandatory pre-bid conference and site visit for this project held on Wednesday, December 6, 2023, at 1:00:00 P.M. An RGMK representative will meet potential bidders in front of the Transportation Building (Building 4) on the West side of the Property just prior to check in. Bidders who do not attend or are tardy will not be eligible to bid. The individual attending the job walk must sign in with his/her company name, license classification of said company, full name, phone number and email address. Please ensure all information is legible. The last day for Prebid RFI’s is Tuesday, December 12, 2023, at 4:00:00 P.M. Bids must be accompanied by a bidder’s bond, cashier’s check, or certified check for at least ten percent (10%) of the amount of the base bid and made payable to the Owner, as detailed in the Contract Documents. Owner, or its designee, has determined that certain materials, services, products or things designated by specific brand or trade name shall not be subject to Public Contract Code section 3400(a) in order that a field test or experiment may be made to determine the product’s suitability for future use; in order to match other materials, services, products or things in use on a particular Owner public improvement either completed or in the course of completion; in order to obtain a necessary item that is only available from one source; and in order to respond to an emergency declared by Owner. These specific materials, services, products or things are identified in the contract documents. Pursuant to the Contract Documents, the successful bidder will be required to furnish a Payment (Labor and Material) Bond in the amount of one hundred percent (100%) of the Contract Sum, and a Faithful Performance Bond in the amount of one hundred percent (100%) of the Contract Sum. The successful bidder will be allowed to substitute securities or establish an escrow in lieu of retainage, pursuant to Public Contract Code Section 22300, and as described in the Agreement Between Owner and Contractor and General Conditions. The Owner will not consider or accept any bids from contractors who are not licensed to do business in the State of California, in accordance with the California Public Contract Code, providing for the licensing of contractors. In accordance with Section 3300 of said Code, the bidder shall have a Class “B or applicable C” license and shall maintain that license in good standing through Contract Completion and all applicable warranty periods. For all projects over Twenty-five Thousand Dollars ($25,000), bidder shall state the public works contractor registration number on the Designation of Subcontractors form for each subcontractor performing more than one-half of one percent (0.5%) of the bidder’s total bid. The Director of Industrial Relations of the State of California, in the manner provided by law, has ascertained the general prevailing rate of per diem wages and rate for legal holidays and overtime work. The Contractor must pay for any labor therein described or classified in an amount not less than the rates specified. Information can be accessed at: www.dir.ca.gov/OPRL/DPreWageDetermination.htm. Advertise: Plan Rooms, email blast, website Thursday, November 30, 2023, with the Monterey County Weekly CITY OF PACIFIC GROVE NOTICE OF SECOND READING OF ORDNANCE WEDNESDAY, DECEMBER 6, 2023, AT 6:00 P.M. 300 Forest Avenue, Pacific Grove, CA City of Pacific Grove meetings will be conducted with virtual and in person participation (hybrid). Members of the public may check the City Council website for details on accessing the meeting via the internet, telephone, and Peninsula Channel 25. The City Council will hold a Second Reading of an Ordinance Amending the Classification Schedule. Copies of the full text of the proposed Ordinance can be reviewed at City Hall, 300 Forest Avenue, Pacific Grove, CA or online at http://www.cityofpacificgrove.org/councilagendas _________/s/___________________ BONNIE GAWF, Interim City Clerk Published: November 30, 2023. CITY OF PACIFIC GROVE NOTICE OF SECOND READING OF ORDNANCE WEDNESDAY, DECEMBER 6, 2023, AT 6:00 P.M. 300 Forest Avenue, Pacific Grove, CA City of Pacific Grove meetings will be conducted with virtual and in person participation (hybrid). Members of the public may check the City Council website for details on accessing the meeting via the internet, telephone, and Peninsula Channel 25. The City Council will hold a Second Reading of an Ordinance adding Chapter 23.92 to the Pacific Grove Municipal Code establishing Cannabis Business Zoning Regulations. Copies of the full text of the proposed Ordinance can be reviewed at City Hall, 300 Forest Avenue, Pacific Grove, CA or online at www.cityofpacificgrove.org/councilagendas _________/s/____________________ BONNIE GAWF, Interim City Clerk Published: November 30, 2023.
RkJQdWJsaXNoZXIy MjAzNjQ1NQ==